Welcome to Kyanite Technologies. These Terms and Conditions govern your access to and use of our website, services, training programs, and software solutions. By accessing our website, enrolling in a course, or engaging in a business agreement, you agree to be legally bound by the terms stated herein.

If you do not agree with any part of these terms, we request you to discontinue using our services or accessing our website.

1. Company Overview

Kyanite Technologies is a registered business based in Madurai, Tamil Nadu, offering:

• Custom Software Development Services

• Online and Offline IT Training Programs

• Pre-recorded Course Modules and Digital Resources

• Career Support and Industry-Oriented Skill Development

These Terms apply to all users of our services, including students, clients, business partners, and website visitors.

2. Eligibility

By using our website or services, you confirm that:

• You are at least 18 years old, or using our services under the supervision of a parent/guardian.

• You have the legal capacity to enter into contracts.

• You are not barred by any law from using such services.

3. Training Programs – Online & Offline

a) Course Enrollment

When you enroll in any course (offline at our Madurai center or online via our learning platform), you agree to:

• Provide accurate information during registration.

• Make full payment as per the fee structure.

• Use the content only for personal learning purposes.

• Attend classes, complete assignments, and maintain ethical behavior.

We reserve the right to suspend or terminate access for students found violating course integrity, copying content, or causing disruption.

b) Course Access & Materials

• Access to live and recorded sessions is provided as per the course plan.

• Content must not be shared, copied, or resold.

• Materials may include third-party tools or platforms, governed by their own terms.

c) Certifications

Certificates are issued upon successful completion of the course and associated evaluations, if applicable.

4. Software Development Services

Clients engaging with Kyanite Technologies for software development agree to:

• Provide clear, written requirements for project scope.

• Cooperate with timelines and approvals.

• Make timely milestone or full payments as agreed in the project proposal.

Kyanite Technologies retains the right to:

• Adjust timelines based on requirement changes or client delays.

• Invoice for additional scope not covered in the original agreement.

• Suspend work in case of non-payment or breach of agreement.

All intellectual property rights will remain with Kyanite Technologies unless explicitly transferred by written agreement.

5. Payment Terms

All services must be paid for in full, or as per agreed installments.

• Course fees and software service charges are non-refundable.

• Payments can be made via UPI, card, net banking, or other approved gateways.

• Failure to complete payment may result in cancellation of enrollment or suspension of services.

Refer to our Refund Policy for more details.

6. No Refund Policy

Kyanite Technologies maintains a strict no refund policy. Once a payment is made, it is considered final and non-reversible.

This includes:

• Training Course Fees (Online and Offline)

• Software Development Service Charges

• Subscriptions or Access to Digital Content

7. Intellectual Property

All content, including but not limited to: training materials, videos, code samples, designs, website content, logos, and branding, are the intellectual property of Kyanite Technologies.

Users are not allowed to:

• Reproduce, distribute, or publicly display course materials

• Modify or sell any of our intellectual property

• Use our content for commercial purposes without written permission

Violation of these rights may result in legal action.

8. Code of Conduct

All users, students, and clients are expected to:

• Behave respectfully with our instructors, team members, and fellow learners

• Avoid using offensive, discriminatory, or illegal language

• Not misuse the platform or attempt unauthorized access

• Respect timelines, deadlines, and collaborative communication

We reserve the right to suspend access for anyone found violating these principles.

9. Website Usage

When using www.kyanitetechnologies.in, you agree to:

• Not upload viruses or harmful content

• Not attempt to hack, damage, or disrupt the website

• Not copy or scrape data for commercial purposes

• Use the site for lawful and intended purposes only

We may monitor site usage and take action against suspicious or harmful behavior.

10. Third-Party Services

Some of our services may involve third-party tools (e.g., YouTube, Zoom, Google Forms, Razorpay). These are governed by their own terms and privacy policies. Kyanite Technologies is not liable for any loss, errors, or misuse that arises from third-party platforms.

11. Limitation of Liability

Kyanite Technologies is not liable for:

• Any personal loss, data loss, or technical failure due to user-side issues

• Inaccuracies in user-provided data

• Business loss or revenue impact from software or course delays

• Inability to access digital content due to internet or device failure

While we strive for accuracy and uptime, we do not guarantee that all services will be error-free or continuously available.

12. Policy Modifications

We reserve the right to update these Terms and Conditions at any time without prior notice. The latest version will be available on our website, and it is your responsibility to stay informed of changes.

Continued use of our services after updates implies acceptance of the revised terms.

13. Governing Law

These Terms and Conditions are governed by the laws of the Republic of India, and any disputes shall be subject to the jurisdiction of the courts in Madurai, Tamil Nadu.

14. Contact Information

For any questions, concerns, or legal inquiries, please contact us:

Kyanite Technologies
Palangantham, Byepass Road, Madurai – 625003
Email: info@kyanitetechnologies.in
Phone: +91-8300343450 | +91-7448300828
Website: www.kyanitetechnologies.in